Justia Mississippi Supreme Court Opinion Summaries

Articles Posted in Government Contracts
by
Construction firm Brasfield & Gorrie, LLC, received the prime contract to expand the University of Mississippi Medical Center Children’s Hospital in 2017. Electrical contractor McInnis Electric Company secured the winning bid to install the electrical and low voltage systems package for the project and subsequently signed a subcontract with Brasfield & Gorrie. Terms of the subcontract incorporated the prime contract, which were related to the same project by reference. The contract provided that work was set to begin on the project on February 15, 2018. However, McInnis, was directed not to report on site until June 4, 2018, and, due to delays, was unable to begin until July 23, 2018. As work progressed, the schedule allegedly became delayed as a result of Brasfield & Gorrie’s failure to coordinate the work of the various subcontractors. McInnis averred that Brasfield & Gorrie’s failure to coordinate and facilitate the work of the various subcontractors worsened as the project progressed, and Brasfield & Gorrie experienced turnover in management. This failure allegedly delayed McInnis’s work, which was not on the path toward completion, supposedly through no fault of its own. Construction issues were amplified when on March 11, 2020, Mississippi experienced its first reported case of COVID-19. On April 1, 2020, the Mississippi Governor instituted a shelter in place order in response to the ongoing pandemic, requiring certain nonessential businesses to close and recommending social distancing to reduce the spread of the coronavirus in Mississippi. The children’s hospital was not classified as an existing infrastructure as it was a nonoperational work in progress and thus was not subject to the executive order’s exception to the governmental shutdowns. By May 8, 2020, McInnis had suffered an approximately 40 percent loss in its workforce due to employees testing positive for COVID-19. Despite the decrease in the available workforce, Brasfield & Gorrie demanded McInnis perform under its contractual obligation. McInnis took measures to continue the work. Brasfield & Gorrie further declined requests for accommodation and instead terminated McInnis on May 13, 2020. The case before the Mississippi Supreme Court here stemmed from disagreements and a broken contract between the parties, contesting whether arbitration was appropriate to settle their disputes. The trial court compelled arbitration, and the Supreme Court affirmed. View "McInnis Electric Company v. Brasfield & Gorrie, LLC et al." on Justia Law

by
Jackson, Mississippi Mayor Chokwe Antar Lumumba attempted to veto the Jackson City Council’s refusal to approve the Mayor’s preferred garbage collection contract. The issue this case presented for the Mississippi Supreme Court's review was whether a mayor, in his restricted executive power, could override by veto a negative action of a city council. The Supreme Court found he could not, and upheld the trial court's judgment. View "Lumumba v. City Council of Jackson, Mississippi" on Justia Law

by
Jernigan Copeland Attorneys, PLLC (JCA), a law firm practicing out of Ridgeland, Mississippi, filed suit against Shad White, in his official capacity as auditor for the state of Mississippi, seeking to recover damages for services rendered and for the reimbursement of costs and expenses owed to a public relations firm. A circuit court found that, because discovery had not been completed in the case, genuine issues of material fact remained. Thus, it denied the office of the state auditor’s (OSA) motion to dismiss or, alternatively, for summary judgment. Because JCA failed to submit evidence creating a genuine issue of material fact that the employment contract complied with statutory requirements, and because JCA’s alternative claims were barred by the applicable statute of limitations, the Mississippi Supreme Court reversed the trial court’s denial of summary judgment. View "White v. Jernigan Copeland Attorneys, PLLC" on Justia Law

by
Broadband Voice, LLC, d/b/a Fuse.Cloud, LLC (Fuse), appealed a Mississippi circuit court's dismissal of its complaint with prejudice. Fuse entered into four contracts with Jefferson County for telephone and internet installation and services. In January 2020, an entirely new board of supervisors took office. The County notified Fuse on November 3, 2020, that it would be terminating the contracts entered into by the 2019 board of supervisors. The termination was to take effect on November 16, 2020. Fuse notified the new board of supervisors that an early-termination fee of $116,984.02 would be imposed if the County terminated the contracts. Fuse disconnected the County’s service before the November 16, 2020 termination date, and sued when the County refused to pay the fee. On August 23, 2021, the circuit court dismissed Fuse’s complaint with prejudice, finding that there were no triable issues. Fuse argued on appeal to the Mississippi Supreme Court that it was entitled to $116,984.02 in early-termination fees from the four contracts. Finding that the early-termination-fee provision was negotiated by the prior board, and that prior board could not limit the ability of a subsequent board to terminate that provision or any other provision of the four contracts, the Supreme Court held the early-termination fee was not enforceable. The circuit court's dismissal was affirmed. View "Broadband Voice, LLC d/b/a Fuse.Cloud, LLC v. Jefferson County, Mississippi" on Justia Law

by
Broadband Voice, LLC, d/b/a Fuse.Cloud, LLC (Fuse), appealed a circuit court's dismissal of its complaint with prejudice. Fuse argued that it was entitled to $116,984.02 in early-termination fees from the four contracts it had with Jefferson County (the County). Fuse also argued that the trial court erred, inter alia, by denying its motion for judgment on the pleadings. Because the early-termination provision in Fuse’s contract with the County was unenforceable, the Mississippi Supreme Court found trial court did not err by denying Fuse’s motion for judgment on the pleadings or by dismissing Fuse’s complaint with prejudice. View "Broadband Voice, LLC v. Jefferson County, Mississippi" on Justia Law

by
The issue this case presented for the Mississippi Supreme Court's review involved the award of a construction contract by the Mississippi State Port Authority at Gulfport (the MSPA) to the low-bidder, W.C. Fore Trucking, Inc. (Fore). Eutaw Construction Company, Inc. (Eutaw), another bidder, challenged that award, and the Circuit Court of the First Judicial District of Hinds County reversed the MSPA’s decision to award the contract to Fore. The MSPA appealed. The Supreme Court found after review that Fore's errors involved instances in which the error was minor, and the intended correct bid was evident on the face of the bid. Also, Fore’s corrected bid was a decrease in price. For these reasons, the MSPA properly followed Rule 3.106.12.4 in allowing Fore to correct its bid. Its decision was not arbitrary and capricious. The record reflected that the MSPA clearly articulated Fore’s errors, the rules that allowed for the correction of those errors, and the MSPA’s reasons for allowing the corrections. Therefore, the Supreme Court reversed the circuit court’s decision and rendered judgment in favor of the MSPA. View "Mississippi State Port Authority at Gulfport v. Eutaw Construction Company, Inc." on Justia Law

by
In 2012, United Healthcare of Mississippi (United) entered into provider agreements with Mississippi’s fourteen Community Mental Health Centers (CMHCs) to provide Medicaid services under the Division of Medicaid’s (DOM’s) managed care program. From 2012 until 2019, United paid the CMHCs an agreed upon amount for Medicaid services - 100 percent of the medicaid fee schedule rates. In July 2019, United unilaterally imposed a 5 percent rate cut, retroactive to January 1, 2019, and later demanded that the CMHCs refund 5 percent of all payments made from July 1, 2018, through December 31, 2018, all of which totaled more than $1 million. The CMCHs demanded that United immediately cease and desist from the 5 percent rate cut and recoupments. When United refused, the CMHCs filed a Complaint for Damages and Injunctive Relief, specifically requesting, inter alia, a preliminary injunction. United responded with a motion to compel arbitration and to stay the proceedings. After a two-day evidentiary hearing, the circuit court denied United’s motion to compel arbitration, granted the CMHCs’ request for injunctive relief, and issued a preliminary injunction. The limited issues presented to the Mississippi Supreme Court were whether the trial court properly enjoined United from imposing a 5 percent rate cut and whether the trial court erred by denying arbitration. After review, the Supreme Court affirmed the trial court’s decision to grant a preliminary injunction and to deny the motion to compel arbitration. View "United Healthcare of Mississippi Inc. et al. v. Mississippi's Community Mental Health Commissions, et al." on Justia Law

by
Magnolia, a managed care organization that contracted with the State to provide Medicaid services, applied what it saw as a statutory five percent reduction in Medicaid rates to Mississippi’s fourteen regional mental health providers. The regional providers responded by filing a complaint against Magnolia in which they sought injunctive relief and monetary damages. On February 18, 2020, Magnolia Health Plan, Inc., and Cenpatico Behavioral Health, LLC (collectively, “Magnolia”), filed a timely notice of appeal after a circuit court denied Magnolia’s motion to compel arbitration, and granted a preliminary injunction against it in favor of Defendants, Mississippi’s fourteen regional health commissions. The notice of appeal included both orders. As to the first, the order denying Magnolia’s motion to compel arbitration, at oral argument before the Mississippi Supreme Court panel, Magnolia abandoned the issue. As to the second, the order granting Magnolia’s request for a permanent injunction, the order was not a final, appealable judgment. Accordingly, the Supreme Court concluded it did not have jurisdiction for further review. View "Magnolia Health Plan, Inc. et al. v. Mississippi's Community Mental Health Commissions, et al." on Justia Law

by
This case involved a dispute between Liberty Mutual Insurance Company (Liberty Mutual), Hill Brothers Construction Company (Hill Brothers) and the Mississippi Transportation Commission (the Commission) regarding a fuel-adjustment clause (the FAC) in a highway-construction contract. In 2019, the Commission successfully moved to alter or amend the circuit court's judgment. The circuit court vacated its prior entry of partial summary judgment in favor of Liberty Mutual on the issue of liability, effectively denying Liberty Mutual's motion for summary judgment. The Mississippi Supreme Court granted Liberty Mutual's petition for interlocutory appeal. The company argued the 2019 order was entered in violation of the Supreme Court's mandate in Hill Brothers I. The Supreme Court determined the circuit court erred in denying Liberty Mutual's motion on liability. The circuit court's judgement was thus reversed and summary judgment reinstated in favor of the insurance company on the issue of liability. View "Liberty Mutual Insurance Company v. Mississippi Transportation Commission" on Justia Law

by
The City of Biloxi (City), the Secretary of State on behalf of the State of Mississippi (State), and the Board of Trustees of the State Institutes of Higher Learning (IHL) settled an ownership dispute over coastal property leased to a casino, and agreed how to divide the annual casino rent. Seventeen years later, the City asked the chancery court to declare that it could adjust for inflation its base amount of rent received before divvying up its rent with the State and the IHL. But the City’s only support of its new inflation-adjustment claim was the three public entities’ lease with the casino. While the casino lease required the minimum amount of rent owed be adjusted for inflation every five years, the casino lease did not govern how the City, the State, and the IHL were to divide the rent. Instead, the manner in which rent was divided is governed solely by the settlement agreement. And the settlement agreement was silent with respect to an inflation adjustment. The Mississippi Supreme Court found, however, the agreement was clear: the City received a specific sum, and any rent in excess of that exact amount had to be shared with the State and the IHL. View "In the Matter of The Stewardship of the Public Trust Tidelands" on Justia Law